Baldi Bros, Inc. v. United States

In the United States Court of Federal Claims No. 16-536 (Filed: May 12, 2023) ************************************** BALDI BROS, INC., * * Plaintiff, * Motion for Summary Judgment; * Constructive Suspension of Work; v. * Constructive Change; Contract * Interpretation. THE UNITED STATES, * * Defendant. * ************************************** William J. Braun, Braun & Melucci, LLP, La Jolla, CA, counsel for Plaintiff. Vijaya Surampudi, U.S. Department of Justice, Civil Division, Washington, DC, counsel for Defendant. OPINION AND ORDER DIETZ, Judge. Construction contractor Baldi Bros, Inc.…