Wright & Kremers, Inc. v. State
Appellate Division of the Supreme Court of the State of New York
1Opinion of the CourtTaylor, J.
In September, 1928, plaintiff entered into a contract with defendant to construct a shop building on the site of Auburn *261Prison. Plaintiff has a judgment for $30,809.26, mainly for damages resulting from delays caused by the State.
Sections 76 and 78 of article 20 of the contract read as follows: “ If the Contractor is delayed in the completion of his work by any act or neglect of the State, or by changes ordered in the work, or by any cause which the Chief Engineer shall deem to justify the delay as being.beyond the Contractor’s control, then the time of completion shall be extended for such…
2Cases cited8 opinions
- People Ex Rel. Wells Newton Co. v. . CraigNew York Court of Appeals · 1921
- Norcross v. . WillsNew York Court of Appeals · 1910
- Johnson v. . City of New YorkNew York Court of Appeals · 1921
- Johnson v. City of New YorkAppellate Division of the Supreme Court of the State of New York · 1920
- W. L. Waples Co. v. StateAppellate Division of the Supreme Court of the State of New York · 1917
3 more not listed; retrieve them via the Exa API.
3Cited by12 opinions
- Kalisch-Jarcho, Inc. v. City of New YorkNew York Court of Appeals · 1983
- Corinno Civetta Construction Corp. v. City of New YorkNew York Court of Appeals · 1986
- Peckham Road Co. v. StateAppellate Division of the Supreme Court of the State of New York · 1969
- Shore Bridge Corp. v. StateNew York Court of Claims · 1946
- D'Angelo v. StateNew York Court of Claims · 1951
7 more not listed; retrieve them via the Exa API.