Peckham Road Co. v. State
Appellate Division of the Supreme Court of the State of New York
1Per curiam
The State of New York appeals from a judgment in favor of the claimant based upon an alleged unreasonable delay by the State in a road construction project.
There is no substantial dispute as to the facts. On February 8,1961 the respondent and the State of New York entered into a contract for the reconstruction of a portion of the Ossining-Kitchawan State Highway. Under the terms of the contract, the respondent was required to construct a new highway and to reconstruct portions of the existing highway for a distance of 2.38 miles. The new highway grade proceeded through the Hess and…
2Cases cited10 opinions
- People Ex Rel. Wells Newton Co. v. . CraigNew York Court of Appeals · 1921
- Norcross v. . WillsNew York Court of Appeals · 1910
- Cauldwell-Wingate Co. v. StateNew York Court of Appeals · 1938
- Wilson & English Construction Co. v. New York Central RailroadAppellate Division of the Supreme Court of the State of New York · 1934
- Wright & Kremers, Inc. v. StateNew York Court of Appeals · 1934
5 more not listed; retrieve them via the Exa API.
3Cited by22 opinions
- Kalisch-Jarcho, Inc. v. City of New YorkNew York Court of Appeals · 1983
- Alvord & Swift v. Stewart M. Muller Construction Co.New York Court of Appeals · 1978
- Corinno Civetta Construction Corp. v. City of New YorkNew York Court of Appeals · 1986
- Dynamics Corp. of America v. International Harvester Co.District Court, S.D. New York · 1977
- Fehlhaber Corp. & Horn Construction Co. v. StateAppellate Division of the Supreme Court of the State of New York · 1978
17 more not listed; retrieve them via the Exa API.