Nelson v. Pickwick Associated Co.
Appellate Court of Illinois
Appeal from the Superior Court of Cook County; the Hon. Egbert Jamieson, Judge, presiding,
1Opinion of the CourtGary, J.
Between these parties a contract was made July 12, 1886, by which the appellant undertook to do the painting and glazing of a building being erected by the appellees. The specifications of the work provided that it should be completed by February 15, 1887, and that §25 per day should be deducted from the contract price for every day the work should remain undone after that date. Also that appellant should co-operate with the contractors for the other parts, and arrange and carry on his work in such a manner that none of the co-operating contractors should bo delayed. These portions of the…
2Cases cited4 opinions
- Wood v. Fort WayneSupreme Court of the United States · 1886
- Bishop v. BusseIllinois Supreme Court · 1873
- Cooke v. MurphyIllinois Supreme Court · 1873
- See v. PartridgeThe Superior Court of New York City · 1853
3Cited by20 opinions
- Guerini Stone Co. v. P. J. Carlin Construction Co.Supreme Court of the United States · 1916
- Del Genovese v. Third Avenue RailroadAppellate Division of the Supreme Court of the State of New York · 1897
- Goss v. Northern Pacific Hospital Ass'nWashington Supreme Court · 1908
- JJ Brown Co., Inc. v. JL Simmons Co., Inc.Appellate Court of Illinois · 1954
- W.H. Stubbings Co. v. World's Columbian Exposition Co.Appellate Court of Illinois · 1903
15 more not listed; retrieve them via the Exa API.