Sutter Corp. v. Tri-Boro Municipal Authority

WATKINS, Judge:

This case comes to us on appeal from the Court of Common Pleas of Susquehanna County and involves plaintiff-appellant’s appeal from a decision of the court below which found in favor of the defendant-appellee and held that it was entitled to retain the sum of $59,300 in liquidated damages on its contract with plaintiff. Defendant had filed an Answer and Counterclaim to plaintiff’s Complaint. The total contract price was $829,071.89.

Plaintiff, a contractor, and defendant, a municipal authority, entered into a written, public construction contract for the construction of an…