Wm. Eisenberg & Sons, Inc. ex rel. Aetna Casualty & Surety Co. v. United States

Plaintiff sues for alleged breaches of contract in connection with the construction of the Beach City Dam in Ohio. Plaintiff claims (1) that it was required to place in the dam materials excavated from other portions of the work, instead of being allowed to waste these materials in spoil areas; (2) that the defendant permitted another contractor to interfere with its construction of a dike; (3) that defendant delayed securing the relocation of a railroad that ran through the dam site; and (4) that for a substantial amount of the trench excavation defendant refused to pay it the price…