Legal Opinion
County Commissioners v. J. Roland Dashiell & Sons, Inc.
Court of Appeals of Maryland
Decided February 11, 2000No. 81, Sept. Term, 1999PublishedCited by 200 opinions
1Opinion of the Court
CATHELL, Judge.
On July 10, 1997, J. Roland Dashiell & Sons, Inc. (Dashiell), respondent, filed a complaint in the Circuit Court for Caroline County against the County Commissioners of Caroline County (County), petitioner, and Greenhorne & O’Mara, Inc. (Greenhorne), claiming damages in excess of $2,000,000.00 for the alleged extra cost of work and delays and seeking the payment of $326,621.00 withheld by the County as liquidated damages pursuant to the Standard Form of Agreement Between Owner and Contractor dated February 22, 1994 (Dashiell Contract).
On August 5, 1997, respondent filed an…
2Cases cited74 opinions
- Clark-Fitzpatrick, Inc. v. Long Island Rail RoadNew York Court of Appeals · 1987
- Heat & Power Corp. v. Air Products & Chemicals, Inc.Court of Appeals of Maryland · 1990
- Beatty v. Trailmaster Products, Inc.Court of Appeals of Maryland · 1993
- King v. BankerdCourt of Appeals of Maryland · 1985
- Henry S. Bloomgarden v. Charles B. CoyerCourt of Appeals for the D.C. Circuit · 1973
69 more not listed; retrieve them via the Exa API.
3Cited by200 opinions
- Hill v. Cross Country Settlement, LLCCourt of Appeals of Maryland · 2007
- J.E. Dunn Constraction Co. v. S.R.P. Development Ltd. PartnershipDistrict Court, D. Maryland · 2015
- Swedish Civil Aviation Admin. v. Project Management Enterprises, Inc.District Court, D. Maryland · 2002
- Benson v. StateCourt of Appeals of Maryland · 2005
- Berry & Gould v. BerryCourt of Appeals of Maryland · 2000
195 more not listed; retrieve them via the Exa API.