G.R. Sponaugle & Sons, Inc. v. Hunt Construction Group, Inc.

MEMORANDUM

CALDWELL, District Judge.

I. Introduction.

Plaintiff, G.R. Sponaugle & Sons, Inc., was the electrical subcontractor for defendant, Hunt Construction Group, Inc., the general contractor for the construction of the Giant Center (“the project”), a 306,-000-square-foot indoor arena in Hershey, Pennsylvania. The project fell behind schedule, occasioning additional costs for Sponaugle not contemplated by the subcontract. In this diversity action controlled by Pennsylvania law, Sponaugle is attempting to recover those additional costs, which it attributes to Hunt’s delay in seeing the…