Johnson, Drake & Piper, Inc. v. State

On December 14, 1962 claimant herein duly filed a claim to recover damages for breach of a highway construction contract in which it seeks to recover the sum of $561,019.32 with appropriate interest. The claim is predicated on the reasonable value of work, labor and materials furnished and expenses incurred in connection therewith as a result of the defendant’s alleged active interference and disruption of the orderly completion of the contract, all stated by claimant to have been in violation of the terms of said contract. Claimant, in addition, seeks the return of bonds of the par value of…