Industrial Power Systems, Inc. v. Kraft Heinz Food Co. LLC

IN THE UNITED STATES DISTRICT COURT FOR THE NORTHERN DISTRICT OF OHIO WESTERN DIVISION Industrial Power Systems, Inc., Case No. 3:22 CV 1703 Plaintiff, MEMORANDUM OPINION -vs- JUDGE JACK ZOUHARY Kraft Heinz Food Co. LLC, Defendant. INTRODUCTION This case stems from a construction project plagued with delays and change orders. After the Project concluded, Plaintiff Industrial Power Systems (“IPS”) recorded a mechanic’s lien and brought claims for breach of contract, unjust enrichment, and lien enforcement. Defendant Kraft Heinz Food Co. (“Kraft”) counterclaimed, asserting that IPS breached the…