Legal Opinion
Hunt Construction Group, Inc. v. National Wrecking Corporation
District Court, District of Columbia
Decided April 8, 2008No. Civil Action No. 05-165 (RMC)PublishedCited by 10 opinions
1Opinion of the Court
MEMORANDUM OPINION
ROSEMARY M. COLLYER, District Judge.
Hunt Construction Group, Inc. (“Hunt”) and National Wrecking Corporation (“NWC”) entered into a construction subcontract whereby NWC agreed to provide certain excavation services at a project located in downtown Washington, D.C. The United States Surety Company (“USSC”) and XL Reinsurance America, Inc. (“XL”) (collectively the “Sureties”) provided a performance bond with Hunt as the obligee and NWC as the principal/obligor. NWC allegedly caused delays in the project, so that, months after it had completed its work, Hunt “terminated” its…
2Cases cited22 opinions
- Anderson v. Liberty Lobby, Inc.Supreme Court of the United States · 1986
- Celotex Corp. v. Catrett, Administratrix of the Estate of CatrettSupreme Court of the United States · 1986
- Grupo Dataflux v. Atlas Global Group, L. P.Supreme Court of the United States · 2004
- Casper Eugene Harding v. Vincent GrayCourt of Appeals for the D.C. Circuit · 1993
- Dennis Diamond, Appellee/cross-Appellant v. Brian Atwood, Administrator, Agency for International Development, Appellant/cross-AppelleeCourt of Appeals for the D.C. Circuit · 1995
17 more not listed; retrieve them via the Exa API.
3Cited by10 opinions
- Hunt Construction Group, Inc. v. National Wrecking CorporationCourt of Appeals for the D.C. Circuit · 2009
- Nova Casualty Co. v. Turner Construction Co., Texas Court of Appeals, 14th District (Houston)2011
- Flatiron-Lane v. Case Atlantic Co.District Court, M.D. North Carolina · 2015
- Sheet Metal Workers' Local Union No. 100 Washington, D.C. Area Pension Fund v. Western Surety Co.District Court, D. Maryland · 2016
- County of Brunswick v. Lexon InsuranceDistrict Court, E.D. North Carolina · 2010
5 more not listed; retrieve them via the Exa API.