Torres v. United States

Plaintiff sues for damages for breach of his contract with the defendant for certain construction at the Eoosevelt Eoads project in Puerto Eico. This project called for the erection of 25 buildings at Daguao Army Base in Puerto Eico. Plaintiff alleges defendant breached .its contract with him in that it delayed .him in the construction of the buildings in three *78ways: first, it failed to stake the site of the buildings in time; second, it changed the design of the buildings; and, third, it failed to furnish the required materials on time.

Plaintiff’s first two claims are untenable; the first,…