Legal Opinion
John Monaghan Inc. v. State Highway Department
Court of Appeals of Georgia
Decided March 3, 1950No. 32827PublishedCited by 4 opinions
1Opinion of the CourtSutton, C. J.
John Monaghan Inc. sued the State Plighway Department in Mitchell Superior Court for damages on account of a delay or stoppage of work on a road-construction contract. According to the petition, the plaintiff and the defendant made a contract on August 20, 1948, for the improvement of approximately 9 miles of road in Mitchell County, and the plaintiff began work on the road under said contract immediately after the contract was signed, and continued to work thereon until October 20, 1948, at which time the defendant, through its duly authorized representative, E. F. Groover Jr., resident…
2Cases cited5 opinions
- United States v. William Cramp & Sons Ship & Engine Building Co.Supreme Court of the United States · 1907
- Coulter v. . Board of EducationNew York Court of Appeals · 1875
- Cascade Automatic Sprinkler Corp. v. StateAppellate Division of the Supreme Court of the State of New York · 1936
- Cascade Automatic Sprinkler Corp. v. StateNew York Court of Claims · 1933
- Dube v. PeckSupreme Court of Rhode Island · 1901
3Cited by4 opinions
- Thyssenkrupp Steel USA, LLC v. United Forming, Inc.District Court, S.D. Alabama · 2013
- American Surety Co. v. Ed Smith & Sons, Inc.Court of Appeals of Georgia · 1959
- American Surety Co. v. Ed Smith & Sons, Inc.Court of Appeals of Georgia · 1959
- Ferro Concrete Construction Co. v. Kentucky Utilities Co.District Court, E.D. Kentucky · 1962