Legal Opinion
Cascade Automatic Sprinkler Corp. v. State
Appellate Division of the Supreme Court of the State of New York
Decided March 21, 1936No. Claim No. 22060PublishedCited by 7 opinions
1Per curiam
Appeal from judgment of the Court of Claims dismissing appellant’s claim upon the merits. I
Appellant had a contract with the State for the installation of the heating plant in certain buildings at Manhattan State Hospital and to furnish temporary heat for these buildings during the process of construction, which contract was to be completed on December 31, 1928. Due to delays not caused by the appellant and an extension of the completion date granted by the State to the other contractors, appellant was required to furnish temporary heat to May 1, 1929. The contract provided that the making…
2Cases cited3 opinions
- Cauldwell-Wingate Company v. City of New YorkNew York Court of Appeals · 1935
- Afgo Engineering Corp. v. StateAppellate Division of the Supreme Court of the State of New York · 1935
- Afgo Engineering Corporation v. State of New YorkNew York Court of Appeals · 1935
3Cited by7 opinions
- Humphreys v. J. B. Michael & Co.Court of Appeals of Kentucky (pre-1976) · 1960
- John Monaghan Inc. v. State Highway DepartmentCourt of Appeals of Georgia · 1950
- Podzuweit v. StateNew York Court of Claims · 1948
- Cascade Automatic Sprinkler Corp. v. StateAppellate Division of the Supreme Court of the State of New York · 1936
- Cascade Automatic Sprinkler Corp. v. StateAppellate Division of the Supreme Court of the State of New York · 1936
2 more not listed; retrieve them via the Exa API.