Legal Opinion
Northeast Drilling, Inc. v. Inner Space Services, Inc.
Court of Appeals for the First Circuit
Decided March 16, 2001No. 00-1684PublishedCited by 38 opinions
1Opinion of the Court
STAHL, Circuit Judge.
During the construction of a shipbuilding facility in Bath, Maine, a series of events, primarily attributable to the caprices of nature, delayed the schedule, forcing significant alterations to the work plan and ultimately making the project more expensive than had been anticipated. These events led to a dispute between the project’s dredging subcontractor, Inner Space Services, Inc. (“ISSI”), and the drilling and blasting subcontractor it had hired, Northeast Drilling, Inc. (“NDI”), over who should bear the additional costs arising from these various matters. Following a…
2Cases cited29 opinions
- Anderson v. City of Bessemer CitySupreme Court of the United States · 1985
- United States v. Ilario M.A. ZanninoCourt of Appeals for the First Circuit · 1990
- Mulero Rodriguez v. Ponte, Inc.Court of Appeals for the First Circuit · 1996
- United States v. New York, New Haven & Hartford RailroadSupreme Court of the United States · 1957
- Commercial Union Insurance v. Seven Provinces InsuranceCourt of Appeals for the First Circuit · 2000
24 more not listed; retrieve them via the Exa API.
3Cited by38 opinions
- Eplus Technology, Incorporated v. Patricia Aboud, A/K/A Carole Girard, and Daniel Jacques Akerib Jean-Marie Chartuny George Bernachawy John DoeCourt of Appeals for the Fourth Circuit · 2002
- Nieto v. KapoorCourt of Appeals for the Tenth Circuit · 2001
- Bogosian v. Woloohojian Realty Corp.Court of Appeals for the First Circuit · 2003
- Federal Insurance Co v. HPSC, Inc.Court of Appeals for the First Circuit · 2007
- Phillip v. Marsh-MonsantoSupreme Court of The Virgin Islands · 2017
33 more not listed; retrieve them via the Exa API.