Legal Opinion
Hutton Construction, Inc. v. Continental Western Insurance Company
District Court, D. New Hampshire
Decided July 5, 2022No. 21-cv-706-PBPublishedCited by 1 opinion
1Opinion of the Court
UNITED STATES DISTRICT COURT FOR THE DISTRICT OF NEW HAMPSHIRE Hutton Construction, Inc. v. Case No. 21-cv-706-PB Opinion No.
2022 DNH 076
Continental Western Insurance Company MEMORANDUM AND ORDER This insurance coverage case stems from a subcontractor’s defective masonry work. The principal issue presented by the insurer’s motion for partial summary judgment is whether the subcontractor’s comprehensive general liability policy covers stipulated delay damages that the general contractor incurred when the subcontractor’s faulty work caused a building inspector to issue a stop-work order for the…
2Cases cited40 opinions
- Celotex Corp. v. Catrett, Administratrix of the Estate of CatrettSupreme Court of the United States · 1986
- Kvaerner Metals Division of Kvaerner US, Inc. v. Commercial Union Insurance CompanySupreme Court of Pennsylvania · 2006
- Lamar Homes, Inc. v. Mid-Continent Casualty Co.Texas Supreme Court · 2007
- American Family Mutual Insurance v. American Girl, Inc.Wisconsin Supreme Court · 2004
- Cherkaoui v. City of QuincyCourt of Appeals for the First Circuit · 2017
35 more not listed; retrieve them via the Exa API.
3Cited by1 opinion
- Hutton Construction, Inc. v. Continental Western Insurance CompanyDistrict Court, D. New Hampshire · 2022