Legal Opinion
Gilchrist Construction Co. v. State, Department of Transportation & Development
Louisiana Court of Appeal
Decided March 9, 2015No. 2013 CA 2101PublishedCited by 7 opinions
1Opinion of the CourtGuidry, J.
|2In this dispute concerning the scope of work and payment of delay damages on a public highway project, the Louisiana Department of Transportation and Development (DOTD) appeals an adverse judgment holding it liable for additional compensation.
FACTS AND PROCEDURAL HISTORY
This dispute arises out of a public works contract executed on February 6, 2007, by the defendant public entity, the DOTD, and the plaintiff contractor, Gilchrist Construction Company, LLC, for the performance of work necessary to widen Interstate 10 east of Lake Charles, Louisiana, in accordance with plans and…
2Cases cited11 opinions
- Daubert v. Merrell Dow Pharmaceuticals, Inc.Supreme Court of the United States · 1993
- Cheairs v. State Ex Rel. DOTDSupreme Court of Louisiana · 2003
- Nicon, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 2003
- PELTS & SKINS EXPORT v. StateLouisiana Court of Appeal · 1999
- Gaines v. BruscatoLouisiana Court of Appeal · 1998
6 more not listed; retrieve them via the Exa API.
3Cited by7 opinions
- Barringer v. RobertsonLouisiana Court of Appeal · 2015
- Fonseca v. City Air of Louisiana, LLCLouisiana Court of Appeal · 2016
- MP31 Investments, LLC v. Harvest Operating, LLCLouisiana Court of Appeal · 2016
- Cajun Constructors, Inc. v. Ecoproduct Solutions, LPLouisiana Court of Appeal · 2015
- Lambert Gravel Co. v. Parish of West Feliciana ex rel. West Feliciana Parish Police JuryLouisiana Court of Appeal · 2016
2 more not listed; retrieve them via the Exa API.