Legal Opinion
Law Co., Inc. v. MOHAWK CONST. AND SUPPLY CO.
Court of Appeals for the Tenth Circuit
Decided August 17, 2009No. 08-3076PublishedCited by 86 opinions
1Opinion of the Court
LUCERO, Circuit Judge.
The Law Company, Inc. (“Law”), a general contractor, sought a declaratory judgment that one of its subcontractors, Mohawk Construction and Supply Company, Inc. (“Mohawk”), is barred from collecting delay damages under the parties’ subcontract. Mohawk counterclaimed for breach of contract. On summary judgment, the district court refused to consider two affidavits and numerous documents submitted by Mohawk and declined to address several of Mohawk’s legal arguments. After excluding these submissions, the district court granted summary judgment in favor of Law.
For the…
2Cases cited22 opinions
- Ralston v. Smith & Nephew Richards, Inc.Court of Appeals for the Tenth Circuit · 2001
- Franks v. NimmoCourt of Appeals for the Tenth Circuit · 1986
- Metzler v. Federal Home Loan BankCourt of Appeals for the Tenth Circuit · 2006
- Wilson v. MuckalaCourt of Appeals for the Tenth Circuit · 2002
- Howard v. WaideCourt of Appeals for the Tenth Circuit · 2008
17 more not listed; retrieve them via the Exa API.
3Cited by86 opinions
- Bixler v. FosterCourt of Appeals for the Tenth Circuit · 2010
- John Daubert v. NRA Group LLCCourt of Appeals for the Third Circuit · 2017
- Hernandez v. Valley View Hospital Ass'nCourt of Appeals for the Tenth Circuit · 2012
- Knitter v. Corvias Military Living, LLCCourt of Appeals for the Tenth Circuit · 2014
- Quinton Harris v. Union Pacific Railroad CompanyCourt of Appeals for the Eighth Circuit · 2020
81 more not listed; retrieve them via the Exa API.