Maghie Savage, Inc. v. P.J. Dick Inc., 08ap-487 (5-5-2009)

OPINION

{¶ 1} Plaintiff-appellant, Maghie Savage, Inc. ("MS"), appeals from the Franklin County Court of Common Pleas' judgment on a directed verdict in favor of defendant-appellee, P.J. Dick Inc. ("PJD"), and entry of summary judgment in favor of defendant-appellee, Blakley Corporation ("Blakley"). For the following reasons, we affirm.

{¶ 2} This action arises out of the construction of the Austin Knowlton School of Architecture (the "project") at The Ohio State University ("OSU"). Construction began in June 2002 and was originally scheduled for completion in April 2004. The completion date…