Case Prestressing Corp v. Chicago College of Osteopathic Medicine

PRESIDING JUSTICE ROMITI

delivered the opinion of the court:

Third-party plaintiff-appellant George A. Fuller Company (Fuller) was the contractor on a project for Chicago College of Osteopathic Medicine (the college). Schmidt, Garden & Erikson was the architect (the architect.) After completion of the project, the college sued Fuller in Federal court for breach of contract; Fuller counterclaimed against the college for breach of contract and filed a claim against the college for breach of contract and filed a claim against the architect for causing it to suffer delay damages. Claims relating to…