Southern Building Services, Inc. v. City of Fort Smith

BILL H. WALMSEY, Judge.

| iThis casé involves a construction dispute between appellant Southern Building Services, Inc. (“SBS”), and appellee City of Fort Smith, Arkansas (“City”). Following a three-day bench trial, the circuit court awarded the City liquidated damages of $134,250, plus interest at the rate of 6% per annum from June 18, 2008, for SBS’s failure to timely achieve substantial completion of the project. It also awarded the City $30,999.96 for the cost of completing the project and $51,262 for attorney’s fees. On appeal, SBS argues that the circuit court erred in each of those…