Schuler-Haas Electric Corp. v. Wager Construction Corp.
Appellate Division of the Supreme Court of the State of New York
1Opinion of the Court
Order unanimously affirmed, without costs. Memorandum: Plaintiff was the electrical subcontractor of defendant Wager Construction Corporation in the construction of the Wilson Commons Building, owned by defendant Dormitory Authority, at the University of Rochester. During the construction, Wager assigned its contract to defendant Rouse Construction Company. The remaining defendants are the bonding companies. Plaintiff brings this action to recover for damages for costs incurred as the result of change orders, delays in construction, and alleged interference with the performance of its…
2Cases cited6 opinions
- Custer Builders, Inc. v. Quaker Heritage, Inc.Appellate Division of the Supreme Court of the State of New York · 1973
- Robbins v. Frank Cooper AssociatesNew York Court of Appeals · 1964
- Robbins v. Frank Cooper AssociatesAppellate Division of the Supreme Court of the State of New York · 1963
- Alko Manufacturing Corp. v. Neptune Meter Co.Appellate Division of the Supreme Court of the State of New York · 1964
- Alko Manufacturing Corp. v. Neptune Meter Co.New York Court of Appeals · 1965
1 more not listed; retrieve them via the Exa API.
3Cited by30 opinions
- EFCO Corp. v. U.W. Marx, Inc.Court of Appeals for the Second Circuit · 1997
- Michael Kolentus v. Avco Corporation and Avco Precision Products Division, Avco Corporation, and Chemical BankCourt of Appeals for the Seventh Circuit · 1986
- Contelmo's Sand & Gravel, Inc. v. J & J Milano, Inc.Appellate Division of the Supreme Court of the State of New York · 1983
- Nepco Forged Products, Inc. v. Consolidated Edison Co.Appellate Division of the Supreme Court of the State of New York · 1984
- Wrenn v. New York City Health & Hospitals Corp.District Court, S.D. New York · 1985
25 more not listed; retrieve them via the Exa API.