J. F. Allen Co. v. Department of Highways

WALLACE, JUDGE:

The claimant filed this claim against the respondent for recovery of $25,500.00 assessed against it as liquidated damages and for interest due on other payments delayed after the prescribed statutory period.

The claimant was the successful bidder and was awarded a contract to construct a portion of U.S. Route 48 extending from Morgantown, West Virginia, into the State of Maryland. The contract was for two projects, APD-483(21) and APD-483(22), hereinafter referred to as Project 21 and Project 22. The contract was let on April 27, 1971, and awarded May 3, 1971.

Project 21…