Frederick Engineering Co. v. State Road Commission

DUCKER, JUDGE:

The claimant, Frederick Engineering Company, a corporation, ■alleges that the State Road Commission owes it $21,720.00 as money withheld by the Road Commission as liquidated damages for 181 days at $120 per day for claimant’s failure to complete within the specified time its work on the contract which was awarded to claimant on May 8, 1961, for the construction of approximately 7,381 feet of Interstate Highway 77 in Wood County, West Virginia, just south of Parkersburg, and being known as Project 1-77 (28) Contract No. 1.

The contract specified that it was to be completed in 225…