State v. Snyder

— This action was brought by appellee, a partnership, in the Marion Superior Court, sitting as a court of claims. The complaint purports to be drawn on the theory of a breach of a highway construction contract entered into by appellee partnership with the State of Indiana, through the Indiana State Highway Commission, for the construction of project No. 74B on a state road between Lebanon and LaFayette; the alleged breach relied upon being delay in procuring the right of way.

The issues were joined on appellee’s amended complaint and appellant’s six paragraphs of answer, which answer was filed…