Legal Opinion
Addicks Services, Inc. v. GGP-BRIDGELAND, LP
Court of Appeals for the Fifth Circuit
Decided February 8, 2010No. 09-20155PublishedCited by 63 opinions
1Opinion of the Court
KING, Circuit Judge:
In this contract action, plaintiff-appellant is a contractor seeking damages for extra work and delay costs incurred performing land improvement for a residential development in Harris County, Texas. The district court granted summary judgment to defendants-appellees, holding that plaintiff-appellant’s claims were barred by waivers and releases it executed monthly to receive progress payments. We affirm.
I. BACKGROUND
GGP-Bridgeland, LP (“Bridgeland”) 1 is the owner of Bridgeland, a residential development in Harris County, Texas. Ad-dicks Services, Inc. (“Addicks”),…
2Cases cited42 opinions
- Anderson v. Liberty Lobby, Inc.Supreme Court of the United States · 1986
- Celotex Corp. v. Catrett, Administratrix of the Estate of CatrettSupreme Court of the United States · 1986
- Matsushita Electric Industrial Co., Ltd. v. Zenith Radio CorporationSupreme Court of the United States · 1986
- Coker v. CokerTexas Supreme Court · 1983
- Marian Fontenot, Etc. v. The Upjohn CompanyCourt of Appeals for the Fifth Circuit · 1986
37 more not listed; retrieve them via the Exa API.
3Cited by63 opinions
- Ressie Moore v. Ford Motor CompanyCourt of Appeals for the Fifth Circuit · 2014
- Philip Cannata v. Catholic Diocese of Austin, et aCourt of Appeals for the Fifth Circuit · 2012
- United States v. Renda Marine, Inc.Court of Appeals for the Fifth Circuit · 2012
- Nickell v. Beau View of Biloxi, L.L.C.Court of Appeals for the Fifth Circuit · 2011
- Lyda Swinerton Builders, Inc. v. Cathay Bank, Texas Court of Appeals, 14th District (Houston)2013
58 more not listed; retrieve them via the Exa API.