Bolton Corp. v. T. A. Loving Co.

ARNOLD, Judge.

This action presents the following issues to this Court: (1) Was there sufficient evidence of negligence to preclude defendant’s motion for directed verdict on that claim? (2) Is the contract provision which identifies Loving as project expediter valid? (3) Is the architect’s allocation of responsibility for delay final, absent bad faith? (4) What theory of damages, and what evidence of damages may be presented? (5) When the State granted a change order for extension of time to Loving, what effect, if any, did that have on Bolton’s claim against Loving for “undue delay”? (6) Was…