Legal Opinion
Gulf Contracting, Inc. v. United States
United States Court of Claims
Decided June 28, 1991No. 90-42CPublishedCited by 10 opinions
1Opinion of the Court
OPINION
MARGOLIS, Judge.
This government contracts case is before the court on cross-motions for summary judgment. Plaintiff contractor entered into a contract to construct buildings for the defendant. The contractor and its subcontractor claim compensation for delay, return of liquidated damages, and reimbursement of interest expenses on borrowings and expert consultant fees, allegedly caused by a change to the contract. The Armed Services Board of Contract Appeals (“ASBCA”) in its first opinion agreed that there was a constructive change to the contract. In its second opinion, the ASBCA…
2Cases cited16 opinions
- Library of Congress v. ShawSupreme Court of the United States · 1986
- United States v. N. Y. Rayon Importing Co.Supreme Court of the United States · 1947
- Fortec Constructors v. The United StatesCourt of Appeals for the Federal Circuit · 1985
- J. D. Hedin Construction Company, Inc., for Its Own Use and for the Use of Fischbach & Moore, Its Sub-Contractor v. The United StatesUnited States Court of Claims · 1965
- Koppers Company, Inc. v. The United StatesUnited States Court of Claims · 1968
11 more not listed; retrieve them via the Exa API.
3Cited by10 opinions
- George Sollitt Construction Co. v. United StatesUnited States Court of Federal Claims · 2005
- Bill Strong Enterprises, Inc. v. John Shannon, Acting Secretary of the ArmyCourt of Appeals for the Federal Circuit · 1995
- ADP Marshall, Inc. v. NORESCO, LLCDistrict Court, D. Rhode Island · 2010
- Scott Timber Co. v. United StatesUnited States Court of Federal Claims · 2011
- City of Miami v. Tarafa Const., Inc.District Court of Appeal of Florida · 1997
5 more not listed; retrieve them via the Exa API.