Legal Opinion
Boston v. NEW ENGLAND SALES & MANUFACTURING CORP.
Massachusetts Supreme Judicial Court
Decided July 21, 1982Published
1Opinion of the Court
386 Mass. 820 (1982)
438 N.E.2d 68
CITY OF BOSTON
vs.
NEW ENGLAND SALES & MANUFACTURING CORPORATION & another[1] (and a companion case[2]).
Supreme Judicial Court of Massachusetts, Suffolk.
April 9, 1982.
July 21, 1982.
Present: WILKINS, LIACOS, NOLAN, & LYNCH, JJ.
Edmund C. Grant, Assistant Corporation Counsel, for the city of Boston, submitted a brief.
WILKINS, J.
In this appeal by the city of Boston, involving a single issue, we must determine whether the city is entitled to contractual liquidated damages for delay after the abandonment of a construction contract by the principal defendant. The city…
2Cases cited9 opinions
- Phaneuf v. CoreyMassachusetts Supreme Judicial Court · 1906
- Oregon, State Highway Com'n v. DeLong Corp.Court of Appeals of Oregon · 1972
- Morrison v. RichardsonMassachusetts Supreme Judicial Court · 1907
- Vaught Construction Corp. v. Bertonazzi Buick Co.Massachusetts Supreme Judicial Court · 1976
- Six Companies of California v. Joint Highway Dist. No. 13Court of Appeals for the Ninth Circuit · 1940
4 more not listed; retrieve them via the Exa API.