Legal Opinion
Phoenix Electrical Contracting, Inc. v. Lehr Construction Corp.
Appellate Division of the Supreme Court of the State of New York
Decided September 7, 1995PublishedCited by 5 opinions
1Opinion of the Court
Judgment, Supreme Court, New York County (Harold Tompkins, J.), entered April 15, 1994, after nonjury trial, in favor of plaintiff subcontractor and against defendant-appellant general contractor in the principal amount of $186,467.64, plus interest from November 3,1987, unanimously modified, on the law and the facts, to reduce the principal amount to $58,888.78, with interest from November 3, 1988, and otherwise affirmed, without costs.
Defendant Lehr, the general contractor on a renovation contract for premises occupied by defendant Rose Associates, should not have been held liable for delay…
2Cases cited5 opinions
- Ford v. Unity HospitalNew York Court of Appeals · 1973
- National Contracting Co. v. Hudson River Water Power Co.New York Court of Appeals · 1908
- AEB & Associates Design Group, Inc. v. Tonka Corp.District Court, S.D. New York · 1994
- Triangle Sheet Metal Works, Inc. v. JAMES H. MERRITT & CO.New York Court of Appeals · 1991
- Gonfiantini v. ZinoAppellate Division of the Supreme Court of the State of New York · 1992
3Cited by5 opinions
- Sequa Corp. v. GBJ Corp.Court of Appeals for the Second Circuit · 1998
- Barry, Bette & Led Duke, Inc. v. StateAppellate Division of the Supreme Court of the State of New York · 1998
- Douglas Construction, Inc. v. MarcaisAppellate Division of the Supreme Court of the State of New York · 1997
- Brian Trematore Plumbing & Heating, Inc. v. Walsh Construction Group, LLCDistrict Court, S.D. New York · 2021
- Sequa Corporation and Sequa Capital Corporation, Plaintiffs-Appellants-Cross-Appellees v. Gbj Corporation, Jeffrey J. Gelmin, and Topaz Capital Corporation, Defendants-Appellees-Cross-Appellants. Gbj Corporation, Jeffrey J. Gelmin, and Topaz Capital Corporation v. Butler, Fitzgerald & Potter, a Professional CorporationCourt of Appeals for the Second Circuit · 1998