K & S Associates, Inc. v. State

OPINION

Montana, C.J.

The Claimant, K & S Associates, Inc., brought this claim on January 4, 1984, seeking $476,110.50 in damages incurred due to delays and other problems Claimant encountered in the performance of a construction contract with the Respondent Capital Development Board (hereinafter referred to as the “CDB”). The case was tried over many months by the Commissioner assigned to the case. The cause was consolidated for trial purposes only with claims by Lippert Brick Contracting, Lowry Electric Company, and Guarantee Electrical Company.

Claimant makes the following claims against the…