Legal Opinion
Cherry Hill Towers, L.L.C. v. Township of Cherry Hill
District Court, D. New Jersey
Decided January 6, 2006No. Civil Action 03-4744 (JEI)PublishedCited by 6 opinions
1Opinion of the Court
OPINION
IRENAS, Senior District Judge.
This lawsuit arises from the events surrounding the application for construction permits by Plaintiff Cherry Hill Towers, LLC (“Plaintiff’ or “Towers”), for the Cherry Hill Towers reconstruction project. Defendant Cherry Hill Township (“Township”) issued the permits three months after the application was submitted, but Plaintiff alleges that the delay caused it to lose over $930,000.
Plaintiff filed the instant Section 1983 complaint against the Defendants Cherry Hill Township, Cherry Hill Township Department of Code Enforcement and Anthony Saccomanno,…
2Cases cited13 opinions
- Anderson v. Liberty Lobby, Inc.Supreme Court of the United States · 1986
- Celotex Corp. v. Catrett, Administratrix of the Estate of CatrettSupreme Court of the United States · 1986
- Matsushita Electric Industrial Co., Ltd. v. Zenith Radio CorporationSupreme Court of the United States · 1986
- United Mine Workers of America v. GibbsSupreme Court of the United States · 1966
- County of Sacramento v. LewisSupreme Court of the United States · 1998
8 more not listed; retrieve them via the Exa API.
3Cited by6 opinions
- Giuliani v. Springfield TownshipDistrict Court, E.D. Pennsylvania · 2017
- E. Rockhill Twp. v. Richard E. Pierson Materials Corp.District Court, E.D. Pennsylvania · 2019
- Allen v. DISTRICT ATTORNEY'S OFF. OF PHILADELPHIADistrict Court, E.D. Pennsylvania · 2009
- Anash, Inc. v. Borough of KingstonDistrict Court, M.D. Pennsylvania · 2024
- Bruce v. City of Pittston, PennsylvaniaDistrict Court, M.D. Pennsylvania · 2023
1 more not listed; retrieve them via the Exa API.