Legal Opinion
Kinetic Builder's, Inc.,appellant v. F. Whitten Peters, Secretary of the Air Force,appellee
Court of Appeals for the Federal Circuit
Decided September 25, 2000No. 00-1065PublishedCited by 34 opinions
1Opinion of the Court
LINN, Circuit Judge.
Kinetic Builder’s Inc. (“Kinetic”) appeals from the consolidated reconsideration decision of the Armed Services Board of Contract Appeals (“Board” or “ASBCA”). See Kinetic Builders, Inc., Nos. 51012 and 51611, 99-2 B.C.A. (CCH) ¶ 30,450, 1999 WL 476692 (ASBCA July 6,1999). In that decision the Board denied Kinetic’s claim for extended job site overhead costs for the delay in contract completion that was caused by the Department of the Air Force’s (“Air Force”) handling of a sewage back-up. In addition, the Board denied Kinetic’s claim seeking a time extension and…
2Cases cited16 opinions
- Bender v. Williamsport Area School DistrictSupreme Court of the United States · 1986
- Flanagan v. United StatesSupreme Court of the United States · 1984
- Placeway Construction Corporation v. The United StatesCourt of Appeals for the Federal Circuit · 1990
- Melvin Wilner, D/B/A Wilner Construction Company v. United StatesCourt of Appeals for the Federal Circuit · 1994
- Richard L. Thoen v. The United StatesCourt of Appeals for the Federal Circuit · 1985
11 more not listed; retrieve them via the Exa API.
3Cited by34 opinions
- Ron Nystrom v. Trex Company, Inc. And Trex Company, LLCCourt of Appeals for the Federal Circuit · 2003
- Norval J. Elkins, Claimant-Appellant v. Hershel W. Gober, Acting Secretary of Veterans AffairsCourt of Appeals for the Federal Circuit · 2000
- Dangfeng Shen Ho v. United StatesUnited States Court of Federal Claims · 2001
- International Electronic Technology Corp. v. Hughes Aircraft Co.Court of Appeals for the Federal Circuit · 2007
- Fireman's Fund Insurance Company v. Gordon R. England, Secretary of the NavyCourt of Appeals for the Federal Circuit · 2002
29 more not listed; retrieve them via the Exa API.