Legal Opinion
Eldor Contracting Corp. v. County of Nassau
Appellate Division of the Supreme Court of the State of New York
Decided April 26, 2004PublishedCited by 5 opinions
1Opinion of the Court
In an action to recover damages for breach of a construction contract, the defendant third-party plaintiff appeals, as limited by its brief, from so much of an order of the Supreme Court, Nassau County (Ort, J.), entered September 26, 2002, as denied its motion for summary judgment dismissing the plaintiff’s second cause of action to recover delay damages, and the third-party defendants separately appeal, as limited by their brief, from so much of the same order as denied that branch of their separate motion which was for summary judgment dismissing that cause of action.
Ordered that the order…
2Cases cited5 opinions
- Wilson & English Construction Co. v. New York Central RailroadAppellate Division of the Supreme Court of the State of New York · 1934
- Clifford R. Gray, Inc. v. City School DistrictAppellate Division of the Supreme Court of the State of New York · 2000
- Icon Motors, Inc. v. Empire State Datsun, Inc.Appellate Division of the Supreme Court of the State of New York · 1991
- Castagna & Son, Inc. v. Board of EducationAppellate Division of the Supreme Court of the State of New York · 1991
- Abax Inc. v. New York City HousIng AuthorityAppellate Division of the Supreme Court of the State of New York · 2001
3Cited by5 opinions
- Travelers Casualty & Surety Co. v. Dormitory Authority-StateDistrict Court, S.D. New York · 2010
- Plato General Construction Corp./EMCO Tech Construction Corp. JV, LLC v. Dormitory AuthorityAppellate Division of the Supreme Court of the State of New York · 2011
- American Architectural, Inc. v. MarinoNew York Supreme Court · 2011
- Henick-Lane, Inc. v. 616 First Ave. LLCAppellate Division of the Supreme Court of the State of New York · 2023
- Henick-Lane, Inc. v. 616 First Ave. LLCAppellate Division of the Supreme Court of the State of New York · 2023