Clifford R. Gray, Inc. v. City School District
Appellate Division of the Supreme Court of the State of New York
1Opinion of the CourtGraffeo, J.
Cross appeals from a judgment of the Supreme Court (Maney, J.), entered July 15, 1999 in Albany County, upon a decision of the court in favor of plaintiff.
The principal issue presented in this litigation between plaintiff, an electrical contractor, and defendant, the owner of a *844school building which was the subject of a renovation project, is whether the “no damages for delay” clause included in the parties’ contract1 is enforceable to bar plaintiff’s claim for money damages for delays that affected the progress and completion of plaintiff’s work on the project. After a nonjury trial, Supreme…
2Cases cited13 opinions
- Kalisch-Jarcho, Inc. v. City of New YorkNew York Court of Appeals · 1983
- Corinno Civetta Construction Corp. v. City of New YorkNew York Court of Appeals · 1986
- A.H.A. General Construction, Inc. v. New York City Housing AuthorityNew York Court of Appeals · 1998
- Berley Industries, Inc. v. City of New YorkNew York Court of Appeals · 1978
- People v. BowmanNew York Court of Appeals · 1994
8 more not listed; retrieve them via the Exa API.
3Cited by22 opinions
- Brodeur v. HayesAppellate Division of the Supreme Court of the State of New York · 2005
- Trataros Construction, Inc. v. New York City Housing AuthorityAppellate Division of the Supreme Court of the State of New York · 2006
- White v. FarrellNew York Court of Appeals · 2013
- Dzek v. Desco Vitroglaze of Schenectady, Inc.Appellate Division of the Supreme Court of the State of New York · 2001
- Roth v. S & H Grossinger, Inc.Appellate Division of the Supreme Court of the State of New York · 2001
17 more not listed; retrieve them via the Exa API.