Goldman v. Kaplan

Winner, J.,

Plaintiff has brought suit on a contract dated October 15, 1942, for alterations to premises 717 West Tioga Street, Philadelphia, the amount of such alterations to cost $1,160. The statement of claim alleges a failure on the part of *685defendant to complete the contract and defective performance in 20 separate items. There is also a claim for rental value of the premises due to the delay in performance. The affidavit of defense denies any defective performance and alleges that the delay was due to an order from the War Production Board which prohibited defendant, the contractor, from…