Legal Opinion
Tufano Contracting Corp. v. State
Appellate Division of the Supreme Court of the State of New York
Decided May 6, 1966No. Claim No. 41888PublishedCited by 7 opinions
1Opinion of the CourtReynolds, J.
This is an appeal by the State from a judgment of the Court of Claims (Simon, J.), awarding the claimant $443,652.98, plus interest, for expenses of constructing additional detours and $19,920.43, plus interest, for delay on the whole project caused by the construction of these extra detours.
On April 14, 1959 claimant contracted with the State to reconstruct 6.11 miles of the Southern State Parkway on Long Island. The original completion date was October 1, 1960, but through extensions granted by the State the work was finally completed in July of 1962. During this period claimant built some…
2Cases cited3 opinions
- Foundation Company v. . State of New YorkNew York Court of Appeals · 1922
- Del Balso Construction Corp. v. City of New YorkNew York Court of Appeals · 1938
- Matter of Stange v. Thompson-Starrett Co.New York Court of Appeals · 1933
3Cited by7 opinions
- Charles T. Driscoll Masonry Restoration Co. v. County of UlsterAppellate Division of the Supreme Court of the State of New York · 2007
- Tutor Perini Corp. v. State of New YorkAppellate Division of the Supreme Court of the State of New York · 2022
- D.A. Elia Construction Corp. v. New York State Thruway AuthorityAppellate Division of the Supreme Court of the State of New York · 2001
- Triple Cities Construction Co. v. StateAppellate Division of the Supreme Court of the State of New York · 1993
- Edenwald Contracting Co. v. City of New YorkAppellate Division of the Supreme Court of the State of New York · 1982
2 more not listed; retrieve them via the Exa API.