Atlanta Economic Development Corp. v. Ruby-Collins, Inc.

Cooper, Judge.

This is a construction contract dispute involving a claim by appellee, a general contractor, against appellant, the owner and developer of an industrial park, for damages resulting from delays in a construction project. We granted this interlocutory appeal to consider whether the trial court erred in denying appellant’s motion for partial summary judgment. In its sole enumeration of error, appellant contends its motion for partial summary judgment on the issue of damages for delay should have been granted because the contract between the parties provided that appellee waived its…