Southwest Engineering Company, a Missouri Corporation v. United States

VAN OOSTERHOUT, Circuit Judge.

Plaintiff Southwest Engineering Company, hereinafter called Southwest, has appealed from summary judgment dismissing its complaint against the United States for recovery of $8,300 withheld as liquidated damages for delay in performance on four construction contracts entered into between Southwest and the United States.

This appeal is before us upon an agreed statement of the record. Four contracts entered into between Southwest and the Government called for the construction by Southwest of three V. O. R. radio facilities at Readsville, Blackwater, and Maryland…