Legal Opinion
Lueder Construction Co. v. Lincoln Electric System
Nebraska Supreme Court
Decided June 3, 1988No. 86-517, 86-518, 86-519PublishedCited by 19 opinions
1Opinion of the CourtCaporale, J.
These appeals arise out of separate suits filed by three construction contractors, appellees Lueder Construction Company (case No. 86-517), Action Electric Company (case No. 86-518), and George H. Wentz, Inc. (case No. 86-519), against the owner, appellant Lincoln Electric System. The contractors aver they suffered damages as the result of delays which they, predictably, claim were caused through the fault of the owner. The owner in turn filed a counterclaim in each case, asserting that it suffered damages as a result of the delays which it, equally predictably, declares were the fault of the…
2Cases cited10 opinions
- Luschen Building Ass'n v. Fleming Companies, Inc.Nebraska Supreme Court · 1987
- Vetter v. Cam Wal Electric Cooperative, Inc.South Dakota Supreme Court · 2006
- State ex rel. Nebraska State Bar Ass'n v. DouglasNebraska Supreme Court · 1987
- Schriner v. Meginnis Ford Co.Nebraska Supreme Court · 1988
- T v. Transmission, Inc. v. City of LincolnNebraska Supreme Court · 1985
5 more not listed; retrieve them via the Exa API.
3Cited by19 opinions
- Knox v. CookNebraska Supreme Court · 1989
- Spittler v. NicolaNebraska Supreme Court · 1992
- Bedrosky v. HinerNebraska Supreme Court · 1988
- Fisbeck v. Scherbarth, Inc.Nebraska Supreme Court · 1988
- Union Pacific Railroad Company v. Brent MowerCourt of Appeals for the Ninth Circuit · 2000
14 more not listed; retrieve them via the Exa API.