Loggins Construction Co. v. Stephen F. Austin State University Board of Regents

McKAY, Justice.

Appellant, Loggins Construction Company (Loggins), brought this suit against Stephen F. Austin State University Board of Regents, appellee (the University), to recover money withheld by the University as liquidated damages on a construction contract for delay in completion for extra work done, and for interest and attorney’s fees. The trial was before the court and the court rendered a take nothing judgment against Loggins, who brings this appeal.

Loggins and the University entered into a written contract for Loggins to build a stadium for the University for a total sum of…