Legal Opinion
Twin Village Construction Corp. v. State
Appellate Division of the Supreme Court of the State of New York
Decided July 13, 1978No. Claim No. 51929Published
1Opinion of the Court
—Judgment unanimously modified in accordance with memorandum and, as modified, affirmed, with costs to claimants. Denman, J., not participating. Memorandum: As low bidder, claimants were awarded a contract for the removal of existing concrete paving and the installation of wider pavement for a length of 2.31 miles of the Tonawanda Creek Road in Niagara County. The contract was dated June 30, 1967 and its completion date was August 14, 1968. Work commenced on July 26, 1967 and was officially accepted on August 4, 1969. The claims relate to additional work in connection with a "borrow”…
2Cases cited6 opinions
- Foundation Company v. . State of New YorkNew York Court of Appeals · 1922
- Cauldwell-Wingate Co. v. StateNew York Court of Appeals · 1938
- Warren Bros. Co. v. New York State Thruway Auth.New York Court of Appeals · 1974
- D'Angelo v. StateNew York Court of Appeals · 1976
- Thomason & Perry, Inc. v. StateAppellate Division of the Supreme Court of the State of New York · 1971
1 more not listed; retrieve them via the Exa API.