Legal Opinion
United States ex rel. Seminole Sheet Metal Co. v. SCI, Inc.
Court of Appeals for the Eleventh Circuit
Decided September 28, 1987No. 86-3477PublishedCited by 21 opinions
1Opinion of the Court
JOHNSON, Circuit Judge:
In this appeal brought under the Miller Act, 40 U.S.C.A. §§ 270a-270d, Seminole Sheet Metal Co., the successor in interest to Floridaire Mechanical Systems, Inc.,1 challenges the district court’s (1) dismissal of counts related to delay damages, (2) denial of an amendment to conform the evidence to the pleadings, and (3) selection of the date upon which to base prejudgment interest. We affirm in part and reverse and remand in part with directions.
*674I.
In 1978, SCI, Inc., and the Veterans Administration (VA) executed a contract for the construction of a hospital in Bay…
2Cases cited16 opinions
- F. D. Rich Co. v. United States Ex Rel. Industrial Lumber Co.Supreme Court of the United States · 1974
- AR Moyer, Inc. v. GrahamSupreme Court of Florida · 1973
- Anthony Cioffe, & Mare Distributors, Inc., a New Jersey Corporation v. Arnold F. Morris & Jet Fingers, Inc., a Florida CorporationCourt of Appeals for the Eleventh Circuit · 1982
- Marsha Lee Wallin, as Administratrix of the Estate of Carl R. Wallin, Deceased v. Allen Ernest Fuller and Nationwide Mutual Insurance CompanyCourt of Appeals for the Fifth Circuit · 1973
- United States of America for the Use of Georgia Electric Supply Company, Inc. v. United States Fidelity and Guaranty CompanyCourt of Appeals for the Fifth Circuit · 1981
11 more not listed; retrieve them via the Exa API.
3Cited by21 opinions
- The United States of America, for the Use of C.J.C., Inc., a New Mexico Corporation v. Western States Mechanical Contractors, Inc., a New Mexico Corporation Commercial Union Insurance Co., a Massachusetts Corporation and Sandia Corporation, a New Mexico Corporation, D/B/A Sandia National Laboratories, United States of America, for the Use of Hugg Surveying Co., Plaintiff v. Western States Mechanical Contractors, Inc., a New Mexico Corporation and Commercial Union Insurance Co., a Massachusetts Corporation, Defendants- United States of America, for the Use of Hugg Surveying Co., Plaintiff v. Western States Mechanical Contractors, Inc., a New Mexico Corporation and Commercial Union Insurance Co., a Massachusetts Corporation, Defendants- the United States of America, for the Use of C.J.C., Inc., a New Mexico Corporation v. Western States Mechanical Contractors, Inc., a New Mexico Corporation and Commercial Union Insurance Co., a Massachusetts Corporation, Defendants- United States of America, for the Use of Fred Sanchez Construction Company v. Western States Mechanical Contractors, Inc., a New Mexico Corporation and Commercial Union Insurance Co., a Massachusetts Corporation, DefendantsCourt of Appeals for the Tenth Circuit · 1987
- United States ex rel. Yonker Construction Co. v. Western Contracting Corp.Court of Appeals for the Eighth Circuit · 1991
- John Doe 6 v. Miami-Dade CountyCourt of Appeals for the Eleventh Circuit · 2020
- United States ex rel. Lochridge-Priest, Inc. v. Con-Real Support Group, Inc.Court of Appeals for the Fifth Circuit · 1992
- Diaz v. Jaguar Restaurant Group, LLCCourt of Appeals for the Eleventh Circuit · 2010
16 more not listed; retrieve them via the Exa API.