D.A. NOLT, INC. v. THE PHILADELPHIA MUNICIPAL AUTHORITY

IN THE UNITED STATES DISTRICT COURT FOR THE EASTERN DISTRICT OF PENNSYLVANIA D.A. NOLT INC,, : Plaintiff, : CIVIL ACTION v . THE PHILADELPHIA MUNICIPAL AUTHORITY et al, : No. 18-4997 Defendants : MEMORANDUM PRATTER, J. JUNE SL. 2022 The City of Philadelphia hired general contractor D.A. Nolt Inc. to redo the roof on the new City police headquarters. Once Nolt finished the roof, after the plans for the new headquarters had been scrapped, the City refused to pay the balance, pointing to delays in completing the project and puddles of water found inside the building once the roof was finished.…