Legal Opinion
International Fidelity Insurance v. County of Rockland
District Court, S.D. New York
Decided May 18, 2000No. 97 CIV. 3711(LMS)PublishedCited by 29 opinions
1Opinion of the Court
MEMORANDUM DECISION AND ORDER
LISA MARGARET SMITH, United States Magistrate Judge.
Plaintiff International Fidelity Insurance Company (“IFIC”) and defendant Fidelity and Guaranty Insurance Company (“F & G”) have both submitted motions for summary judgment in this action, in which several of the parties involved in a construction project dispute who is liable for which portion of the damages resulting from a construction delay. Pursuant to the provisions of 28 U.S.C. § 636(c), the parties have consented to conduct all proceedings in this case before me.
Plaintiff IFIC is a surety company that…
2Cases cited90 opinions
- Celotex Corp. v. Catrett, Administratrix of the Estate of CatrettSupreme Court of the United States · 1986
- W.W.W. Associates, Inc. v. GiancontieriNew York Court of Appeals · 1990
- BFP v. Resolution Trust CorporationSupreme Court of the United States · 1994
- Breed v. Insurance Co. of North AmericaNew York Court of Appeals · 1978
- James M. Cronin v. Aetna Life Insurance CompanyCourt of Appeals for the Second Circuit · 1995
85 more not listed; retrieve them via the Exa API.
3Cited by29 opinions
- Bank of New York Mellon Trust Co. v. Morgan Stanley Mortgage Capital, Inc.Court of Appeals for the Second Circuit · 2016
- Nasik Breeding & Research Farm Ltd. v. Merck & Co.District Court, S.D. New York · 2001
- United States Fidelity And Guaranty Company v. Braspetro Oil Services CompanyCourt of Appeals for the Second Circuit · 2004
- United States Ex Rel. Maris Equipment Co. v. Morganti, Inc.District Court, E.D. New York · 2001
- Leisure Resorts, Inc. v. City of West Palm BeachDistrict Court of Appeal of Florida · 2003
24 more not listed; retrieve them via the Exa API.