Dalton v. Jerico Construction Co.

STEWART, Justice:

This is an appeal from a judgment denying plaintiff Blaine Dalton, dba C & D

Construction Co., delay damages alleged to have been incurred in the performance of a construction contract. Dalton contracted with Jerico to complete work Jerico had contracted to perform under a contract with defendant S. A. Healy Co., a general contractor. The trial court held that Dalton had no right to delay damages which Jerico received from the United States Government, the party which had caused the delay. Dalton contends that the trial court erred in its construction of its subcontract with…