Legal Opinion
M.A. Mortenson Company v. United States
Court of Appeals for the Federal Circuit
Decided April 4, 1988No. 87-1491PublishedCited by 2 opinions
1Opinion of the Court
MARKEY, Chief Judge.
Appeal from a decision of the Corps of Engineers Board of Contract Appeals (board), M.A. Mortenson Co., ENG BCA No. 4780, 87-2 BCA ¶ 19,718 (1987), denying M.A. Mortenson Company’s (Morten-son’s) appeal from the Contracting Officer’s final decision denying compensation for added costs that allegedly resulted from delay in awarding a construction contract. We affirm.
BACKGROUND
In May 1981 the United States Army Corps of Engineers (Corps) issued an invitation for bids (IFB) for construction to rehabilitate Lock and Dam No. 1 on the Mississippi River in Minneapolis, Minnesota.…
2Cases cited4 opinions
- Erickson Air Crane Company of Washington, Inc. v. The United StatesCourt of Appeals for the Federal Circuit · 1984
- P.J. Maffei Building Wrecking Corporation v. The United StatesCourt of Appeals for the Federal Circuit · 1984
- Sidney Kent, Doing Business as Dorald Engineering Company v. United StatesCourt of Appeals for the Second Circuit · 1965
- Kent v. United StatesDistrict Court, S.D. New York · 1964
3Cited by2 opinions
- North Star Alaska Housing Corp. v. United StatesUnited States Court of Federal Claims · 1993
- CEMS, Inc. v. United StatesUnited States Court of Federal Claims · 2003