Legal Opinion
Marine Industrial Construction, LLC v. United States
United States Court of Federal Claims
Decided February 17, 2022No. 15-1189Published
1Opinion of the Court
In the United States Court of Federal Claims No. 15-1189 (Filed: 17 February 2022) *************************************** MARINE INDUSTRIAL CONSTRUCTION, * LLC, * * Plaintiff, * Summary Judgment; Termination for * Default; Termination for Convenience; v. * Conversion; Excusable Delay; Differing Site * Condition; Superior Knowledge; Dredging; THE UNITED STATES, * Reprocurement Costs; Liquidated Damages; * Compensable Delay; Notice; Waiver Defendant. * * *************************************** Joseph A. Yazbeck, Jr., with whom was David H. Bowser, Jordan Ramis PC, all of Lake Oswego, Oregon,…
2Cases cited95 opinions
- Anderson v. Liberty Lobby, Inc.Supreme Court of the United States · 1986
- Celotex Corp. v. Catrett, Administratrix of the Estate of CatrettSupreme Court of the United States · 1986
- Matsushita Electric Industrial Co., Ltd. v. Zenith Radio CorporationSupreme Court of the United States · 1986
- Hercules, Inc. v. United StatesSupreme Court of the United States · 1996
- Gooch v. United StatesSupreme Court of the United States · 1936
90 more not listed; retrieve them via the Exa API.