E Solutions For Buildings, LLC v. Knestrick Contractor, Inc.

04/17/2018 IN THE COURT OF APPEALS OF TENNESSEE AT NASHVILLE March 28, 2018 Session E SOLUTIONS FOR BUILDINGS, LLC v. KNESTRICK CONTRACTOR, INC., ET AL. Direct Appeal from the Chancery Court for Davidson County No. 15-62-IV Russell T. Perkins, Chancellor No. M2017-00732-COA-R3-CV This appeal involves a construction contract dispute among a general contractor, a subcontractor, and the subcontractor’s equipment supplier regarding liability for construction project delays. After a four-day bench trial, the trial court resolved most of the substantive issues among the parties and ultimately…