Metropolitan Steel Industries, Inc. v. Perini Corp.

OPINION OF THE COURT

Buckley, J.

At issue on this appeal is one work order, denominated X-32A, arising out of a construction project, and the applicability of the law of the case doctrine. Defendant Perini Corporation (Perini), the prime contractor on the project, hired plaintiff Metropolitan Steel Industries, Inc. (Steelco) as a subcontractor. Both the prime contract and the subcontract contained a no-damage-for-delay clause, which precluded Steelco from obtaining extra compensation for delays in the project unless specifically allowed by the owner. Steelco began work, but was terminated by…